Mitigation in the construction industry
The term ‘mitigate’ means to make less severe or serious.
This can be important in the construction industry in a number of different circumstances.
- In relation to project delays, it refers to minimising the impact of the risk event (an event or cause of delay or disruption). For example, acceleration might be used to mitigate a delay. Where there is a claim for an extension of time, the contractor may be required to mitigate the delay and any resulting loss, even where the fault is not their own.
- In terms of losses incurred, it can refer to claimant's duty to mitigate their loss. A claimant will generally not be allowed to recover damage which could have been avoided had the claimant acted reasonably. For more information see: Mitigation of loss.
- In relation to planning policy, planning obligations or planning conditions might be used to mitigate or compensate for the negative impacts of a development. For more information see: Planning obligation and planning condition.
- In terms of risks, a contingency plan might be enacted to mitigate project risks, such as adverse weather, industrial disputes and so on. For more information see: Contingency plan.
Mitigation strategies might also be used in relation to:
- Environmental impact.
- Loss of habitat.
- Carbon emissions.
- Flood protection.
- Duty to warn.
A handbook on environmental impact assessment, 4th edition, published by Scottish Natural Heritage in 2013, suggests that:
These are the measures taken to avoid, cancel or reduce adverse impacts of a project. They are:
- Avoidance measures: Designed to avoid or eliminate any adverse impacts arising in the first place, including alternative or ‘do nothing’ options;
- Cancellation measures: Designed to nullify or cancel out any adverse effects of a project before adverse effects are felt;
- Reduction measures: Designed to minimise or at least reduce adverse impacts remaining after avoidance and cancellation measures have been applied to a project.
Culvert, screen and outfall manual, (CIRIA C786) published by CIRIA in 2019, suggests that the mitigation hierarchy is typically:
NB Global Warming of 1.5 ºC, Glossary, published by the Intergovernmental Panel on Climate Change (IPCC) in 2018, defines mitigation (of climate change) as: ‘A human intervention to reduce emissions or enhance the sinks of greenhouse gases.’
[edit] Related articles on Designing Buildings
- Consequential loss.
- Planning condition.
- Planning obligation.
- Contingency plan.
- Risk.
- Environmental impact assessment.
- Relevant event.
- Extension of time.
- Duty to warn in construction.
[edit] External references
- Ref The Society of Construction Law Delay and Disruption Protocol, 2nd edition, published in February 2017 by the Society of Construction Law (UK).
Featured articles and news
Definition of Statutory in workplace and facilities management
Established by IWFM, BESA, CIBSE and BSRIA.
The general election and the construction industry
As PM, Rishi Sunak announces July 4 date for an election.
Tackling the lack of knowledge or confidence in heat pumps
The CICV Green Home Festival part of the Edinburgh Fringe.
Home improvements swapped for green energy upgrades
As applications down since and desire to reduce bills up.
Eco apprenticeships continue help grow green workforce
A year after being recognised at the King's coronation.
The Use of Natural Insulation Materials in Retrofit
New paper from STBA with support from SDF.
National Retrofit Hub in partnership with InstallerSHOW.
Permitted development rights for agricultural buildings
The changes coming into effect as of May 21, 2024.
Biodiversity and the built environment digital series
The nature of building, with CIOB and CWP.
A call for prevention and sensitive re-use.
Risks to the long-term effectiveness of the BNG scheme
National Audit Office publish review of Biodiversity Net Gain.
The CIAT principal designer register
Providing assurance and verification of the capability and competence of registered ATs.
Building Safety recommendations and Northern Ireland
The NI roadmap to improving safety in high rise residential.
Specifying rendered external wall insulation for fire safety
How to interrogate the evidence provided to the specifier.
The benefits of writing articles for your organisation
How to create a profile for your organisation and publish for free.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
A forward thinking, inclusive global community of members.