Octoesse LLP v Trak Special Projects Ltd
The case of Octoesse LLP v Trak Special Projects Ltd. [2016] set an important precedent in ensuring the correct contractual procedures are adhered to when deducting liquidated damages.
Octoesse LLP (the claimant) entered into an amended JCT Intermediate Building Contract with Trak Special Projects Ltd. (the defendant) for the construction of residential units. Practical completion was significantly later than the original completion date, and the defendant submitted a claim for an 18-week extension of time. They were awarded 9.5 weeks by the contract administrator. No further certificate of non completion was issued.
When the defendant issued a final certificate for payment, the claimant issued a pay less notice which deducted liquidated damages. An adjudication was begun by the defendant on the grounds that the pay less notice was invalid.
The case focused on the interpretation of clauses 2.22 and 2.23 which are constructed such that:
'If the Contractor fails to complete the Works or a Section by the relevant Completion Date, the Architect/Contract administrator shall issue a certificate to that effect. If an extension of time is made after the issue of such certificate, the extension shall cancel that certificate and the Architect/Contract Administrator shall where necessary issue a further certificate.'
The defendant argued that it was an express condition of the claimant’s entitlement to deduct liquidated damages that the contract administrator issued a certificate of non completion. Further, the effect of clause 2.22 was that when the extension of time had been given, it had cancelled the certificate of non completion.
Justice Jefford held that the claimant was not entitled to deduct liquidated damages as they had agreed to an extension of time after a certificate of non completion had been issued.
If, on the other hand, the claimant had given notice of their intention to deduct damages, but an extension of time had then been made and a further certificate of non completion issued, then they would not need to give notice of the intention to deduct again.
[edit] Find out more
[edit] Related articles on Designing Buildings Wiki
Featured articles and news
A call for prevention and sensitive re-use.
The CIAT principal designer register
Providing assurance and verification of the capability and competence of registered ATs.
Building Safety recommendations and Northern Ireland
The NI roadmap to improving safety in high rise residential.
BSA residential sector competence standards guidance
BSAS 01:2024 Organisational Capability Management System Standard - Competence Assurance.
Specifying rendered external wall insulation for fire safety
How to interrogate the evidence provided to the specifier.
The benefits of writing articles for your organisation
How to create a profile for your organisation and publish for free.
No Falls Week. The importance of safe working at height
What to expect and what is on offer to avoid accidents.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
A forward thinking, inclusive global community of members.
From engineered product life-spans, to their extension.
Circular economy in the built environment
A brief description from 2021. Where are we now?
CLC publishes domestic retrofit competency framework
Roadmap of Skills for net zero.
Understanding is key to conservation.
Open industry engagement survey seeks responses
Institutions and the importance of engagement.