Early warning notice
See also: NEC early warning notices - a tool of mutual benefit.
The NEC Engineering and Construction Contract 3rd Edition (NEC3) was published in June 2005. It has been adopted as the contract of choice by the government who no longer update the GC Works contracts, and has been endorsed by the ICE whose own suite of contracts will no longer be updated.
The contract makes provision for early warning procedures. Both parties must give early warning of anything that may delay the works, or increase costs as soon as they become aware of them. They should then hold an early warning meeting to discuss how to avoid or mitigate impacts on the project.
If the contractor fails to give early warning of a possible delay to the works, or increase in costs, they will only be compensated for effects that would have remained anyway even if they had given early warning.
If the contractor fails to give early warning of an event that may give rise to a possible delay to the works, or increase in costs, within 8 weeks of becoming aware of the event, they will not be entitled to a change in price, completion date or key date, unless the project manager should have notified the event to the contractor but did not.
They grey area here is whether and when the contractor should have been aware of the event. Judgement is likely to come down to whether and when it would have been reasonable to expect an experienced contractor to be aware of the event.
NB the term 'early warning' can also be used to refer to the identification of a wider hazard such as a climate event. Glossary: Resilience, published by the Department for International Development in 2016, defines an Early Warning System as: ‘The set of capacities needed to generate and disseminate timely and meaningful warning information to enable individuals, communities and organisations threatened by a hazard to prepare and to act appropriately and in sufficient time to reduce the possibility of harm or loss.’
[edit] Related articles on Designing Buildings
- Accepted programme.
- Adversarial behaviour in the UK construction industry.
- Compensation event.
- Delays on construction projects.
- Disallowed cost.
- Duty to warn.
- Extension of time.
- Liquidated damages.
- Loss and expense.
- NEC early warning notices - a tool of mutual benefit.
- NEC3.
- Relevant event.
- Relevant matter.
Featured articles and news
Specifying rendered external wall insulation for fire safety
How to interrogate the evidence provided to the specifier.
The benefits of writing articles for your organisation
How to create a profile for your organisation and publish for free.
No Falls Week. The importance of safe working at height
What to expect and what is on offer to avoid accidents.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
A forward thinking, inclusive global community of members.
From engineered product life-spans, to their extension.
Circular economy in the built environment
A brief description from 2021. Where are we now?
Mental Health Awareness Week with ABS
Architects Benevolent Society programme of activity.
CLC publishes domestic retrofit competency framework
Roadmap of Skills for net zero.
May 13-19: Moving more for our mental health.
Understanding is key to conservation.
Open industry engagement survey seeks responses
Institutions and the importance of engagement.
National Retrofit Hub unveils new guide
Digital Building Logbooks and Retrofit: An Introduction.
Enhancing construction site reporting efficiency
Through digitisation and the digital revolution.
Comments
[edit] To make a comment about this article, or to suggest changes, click 'Add a comment' above. Separate your comments from any existing comments by inserting a horizontal line.