Due diligence
Contents |
[edit] Introduction
In its broadest sense, the term 'due diligence' simply refers to taking reasonable steps or exercising reasonable care in relation to a particular course of action.
In relation to the construction industry, it can have a number of more specific meanings.
[edit] Business assessment
Due diligence can refer to the steps taken to thoroughly investigate a business or person prior to signing a contract with them.
[edit] Technical investigations
Technical due diligence refers to the process of investigating a site to assess its suitability for a particular project and the risks involved before proceeding with that project.
For more information, see Technical due diligence.
[edit] Contractor's obligation
Due diligence may be referred to in a construction contract, placing an obligation on the contractor to complete the works with care and the ‘requisite effort’. A similar term may refer to ‘ordinary care’, that is, the care that a reasonable person would take to avoid harm to other persons or property.
In the case of Sabic UK Petrochemicals Limited v Punj Lloyd Limited, the Technology and Construction Court (TCC) had to examine whether a contractor was in breach of this obligation with regard to the delivery of a petrochemical plant.
The contractor maintained that due diligence required them to maintain an appropriate rate of progress, with regard to the contract requirements, and the completion date that was realistic at the time their rate of progress was being assessed. They claimed that due diligence did not extend to them being obliged to achieve the impossible, and they were not required to accelerate the works to claw back delays.
The TCC disagreed with the contractor and ruled that just because compliance with one or more of the absolute contractual obligations has become unachievable does not mean or imply that these obligations are objectively incapable of achievement. It would be necessary for the contractor to prove the impossibility of complying with the absolute contractual obligation.
They also held that the contractual terms did not suggest that the due diligence obligation should be ‘emptied of content’ as a result of the completion date becoming unachievable. Circumstances may arise, the court found, where the exercising of due diligence may require taking measures not originally contemplated, such as acceleration measures in the case of a delay, if that is what is required.
As a result, it was held that contractual requirement to proceed with ‘due diligence’ imposed strict obligations on the contractor that must be adhered to.
[edit] Related articles on Designing Buildings Wiki
Featured articles and news
The benefits of writing articles for your organisation
How to create a profile for your organisation and publish for free.
No Falls Week. The importance of safe working at height
What to expect and what is on offer to avoid accidents.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
A forward thinking, inclusive global community of members.
From engineered product life-spans, to their extension.
Circular economy in the built environment
A brief description from 2021. Where are we now?
Mental Health Awareness Week with ABS
Architects Benevolent Society programme of activity.
CLC publishes domestic retrofit competency framework
Roadmap of Skills for net zero.
May 13-19: Moving more for our mental health.
Understanding is key to conservation.
Open industry engagement survey seeks responses
Institutions and the importance of engagement.
National Retrofit Hub unveils new guide
Digital Building Logbooks and Retrofit: An Introduction.
Enhancing construction site reporting efficiency
Through digitisation and the digital revolution.
Noise in the built environment
BSRIA guide TG 20/2021.
17,000 people suffer conditions as a result of exposure to excessive noise at work.
Turning down the noise: Auditory health
A pervasive risk with far-reaching consequences.
Getting the most out of heat pumps and heating
How heat pumps work and how they work best.
Electrotechnical excellence, now open for entries.