Global claim
Claims commonly arise between the parties to construction contracts. This can be as a result of problems including; delays, changes, unforeseen circumstances, insufficient information, and conflicts. Claims might be made for loss and expense, extension of time, liquidated damages and so on. The contract should set out what can constitute a claim and how it should be dealt with.
However, as construction is a complex process, there is not always a straight-forward relationship between one particular breach and one specific effect. As a result, in some circumstances, contractors may make a ‘global claim’ by rolling together a number of different breaches and making a case for a cumulative effect resulting in a single total cost without attributing actual costs to specific events.
Global claims have not always found favour with the courts, as they can ignore other reasons for the delay or disruption, and they place the burden of proof on the employer to carry out a detailed assessment of the claim and how it has been constituted.
They can also be counter-challenged by the client, citing contractor’s deficiencies such as; labour shortages, poor management, plant breakdowns and subcontractor non-performance.
Keating on Construction Contracts describes a global claim as ‘...one that provides an inadequate explanation of the causal nexus between the breaches of contract or relevant events/matters relied upon and the alleged loss and damage or delay that relief is claimed for.’
In the case of Walter Lilly v Mackay & DMW (2012), Mr Justice Akenhead said, ‘What is commonly referred to as a global claim is a contractor’s claim which identifies numerous potential or actual causes of delay and/or disruption, a total cost on the job, a net payment from the employer and a claim for the balance between costs and payment which is attributed without more and by inference to the causes of delay and disruption relied upon'
However he went on to quote Mr Justice Donaldson in Crosby v Portland UDC, who stated ‘… it may well be difficult or even impossible to make an accurate apportionment of the total extra cost between the several causative events... I can see no reason why (the arbitrator) should not recognise the realities of the situation and make individual awards in respect of those parts of individual items of the claim which can he dealt with in isolation and a supplementary award in respect of the remainder of the claims as a whole.’
A global claim may be the only route available to the contractor, and the courts may accept this, however, where possible it is considered that it is better to be specific rather than generic. This is a more painstaking exercise requiring that the claimant lists each alleged default, linking it to the delay or disruption and its knock-on effect, all backed by clear records. This is more precise way of establishing quantum and is likely to lead to a more factually-based judgement.
NB, the Society of Construction Law Delay and Disruption Protocol, 2nd edition, defines a global claim as: 'one in which the Contractor seeks compensation for a group of
Employer Risk Events but does not or cannot demonstrate a direct link between the loss
incurred and the individual Employer Risk Events'.
[edit] Related articles on Designing Buildings Wiki
- Alternative dispute resolution.
- Adjudication.
- Arbitration.
- Causes of construction disputes.
- Construction contract.
- Contract claims.
- Dispute resolution boards.
- Extension of time.
- Housing Grants, Construction and Regeneration Act.
- Litigation.
- Liquidated damages.
- Loss and expense.
- Mediation.
- Scheme for Construction Contracts.
Featured articles and news
Industry survey highlights persistent skills gap
Building engineering business survey by ECA in partnership with BESA, SELECT and SNIPEF.
IHBC Conservation Professional Practice Principles
Spotlighted in HEF Historic Environment Overview.
CIAT collaborates with CIOB, CIfA, Icon to launch The Arc
Helping clients find specialist historic environment professionals.
Government building safety remediation data releases
Show some progress, but a 50% gap not yet started.
Testing For A Safer Future; an initial industry response
A response to the Independent Review of the Construction Product Testing Regime.
Requirements for UK buildings in certain circumstances.
CLC guidance for dutyholders and accountable persons.
Types of contractor in the construction industry
A long list, but are any missing ?
The Housing (Cladding Remediation) (Scotland) Bill 2023
Unanimously approved to legislation on May 14, 2024.
Asset information requirements AIR
In detail, with links to further resources.
Where it's AT Building Safety podcasts from CIAT
Unravelling the Golden Thread and CIAT’s Principal Designer Register for non-HRBs and HRBs.
What happened to Hadrian's Wall?
Its former stones can be found in buildings near its route.
Strategic ventilation in modern building design
Download your free guide.
Four new types of prior approval for solar developments
Online Planning Portal application types from 5 September.